...earthquake or cyclone, or by abandonment of the work by employees through no fault of the contractor, then the time herein fixed for the completion of the...shall be extended for a period equivalent to the time Iqst by reason of any or all of the causes aforesaid." Article 8 stipulates that the owner shall pay...

...the owner, or any of the other causes mentioned, the time fixed for the completion of the work should be extended for a period equivalent to the time lost by reason of any or all of said causes, which extended period should be determined and fixed by the architect. By the terms...

...the Contractor, or any other Subcontractor, through no default of the Subcontractor, then the time fixed for the completion of the work shall be extended for a period equivalent to the time lost by any or all of the causes aforesaid, but no such 501 Findings of Fact allowance shall be made unless...

...or cyclone, or by the abandonment of the work by the employes through no fault of the subcontractor, then the time herein fixed for the completion of the...equivalent to the time lost by reason of any or all of the causes aforesaid," etc. This provision makes it clear that delays occasioned the plaintiff by...

...lightning, earthquake or cyclone, or by strikes or lockouts, through no default of the contractor, then the time herein fixed for the completion of the...equivalent to the time lost by reason of any or all of the causes aforesaid, but no such allowance shall be claimed or made unless a claim therefor shall...

...work by the act, neglect, delay, or default of the owner or the architects, » • • then the time fixed for the completion of the work shall be extended...equivalent to the time lost by reason of any or all of the causes aforesaid, but no such allowance shall be made unless a claim therefor is presented in...

...architects or of any other contractor employed by the owner on the work, the time fixed for completion "shall be extended for a period equivalent to the time lost by reason of any or all of the causes aforesaid." But It was' also provided that "no such allowance will be made unless a claim...

...abandonment of the work by the employC-s of the contractor through no fault of theirs, then the time fixed for the completion of the work shall be extended for a period equivalent to the time thus lost," etc. It thus appears that the contractors stipulated what they might claim for themselves...

...prosecution or completion of the work by the act, neglect, or default of the owner or architect that the time herein fixed for the completion of the work shall be extended for a period equal to the time lost by reason of any such cause. But It also provides that no such allowance shall...

...the owner or the architects, or of any other contractor employed by the owner upon the work, * * * then the time herein fixed for the completion of the work shall be extended," etc. The undisputed evidence shows that the contract ] with the brick company was made by the contractors...