The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1949 The Code of federal regulations is the codification of the general and permanent rules published in the Federal register by the executive departments and agencies of the federal government. |
도서 본문에서
50개의 결과 중 6 - 10개
20 페이지
... paid shall be posted by the contractor in a prominent and easily acces- sible place at the site of the work . The con- tracting officer shall have the right to with- hold from the contractor so much of accrued payments as may be ...
... paid shall be posted by the contractor in a prominent and easily acces- sible place at the site of the work . The con- tracting officer shall have the right to with- hold from the contractor so much of accrued payments as may be ...
22 페이지
... paid by the contractor for each calendar day of delay , as indicated in article 9 of the contract . If time is not of the essence of the contract the words " No liquidated damages " or an equivalent phrase should be inserted on the ...
... paid by the contractor for each calendar day of delay , as indicated in article 9 of the contract . If time is not of the essence of the contract the words " No liquidated damages " or an equivalent phrase should be inserted on the ...
36 페이지
... when caused by conditions of loading , shipping , packing , or allowances in manufacturing processes , and payments shall be adjusted accordingly . ART . 8. Payments . The contractor shall be paid Page 36 $ 4.21 Title 41 - Public Contracts.
... when caused by conditions of loading , shipping , packing , or allowances in manufacturing processes , and payments shall be adjusted accordingly . ART . 8. Payments . The contractor shall be paid Page 36 $ 4.21 Title 41 - Public Contracts.
37 페이지
ART . 8. Payments . The contractor shall be paid , upon the submission of properly certi- fied invoices or vouchers , the prices stipu- lated herein for articles delivered and ac- cepted or services rendered , less deductions , if any ...
ART . 8. Payments . The contractor shall be paid , upon the submission of properly certi- fied invoices or vouchers , the prices stipu- lated herein for articles delivered and ac- cepted or services rendered , less deductions , if any ...
40 페이지
... paid by the con- tractor on the articles or supplies herein contracted for , then the prices named in this bid will be increased or decreased accord- ingly , and any amount due the contractor as a result of such change will be charged ...
... paid by the con- tractor on the articles or supplies herein contracted for , then the prices named in this bid will be increased or decreased accord- ingly , and any amount due the contractor as a result of such change will be charged ...
기타 출판본 - 모두 보기
자주 나오는 단어 및 구문
40 hours 49 Stat 58 Stat Act of June active duty Administrator agency airport of entry allotment amended antitoxin applicable appointment approved authorized beds bidder bids bond Business address cents an hour certificate cholera closet commissioned officers contracting officer contractor CORPORATE SEAL disease employees equipment eral established examination executed facilities Federal Security Agency funds furnished Government grade hospital industry inspection June 30 leprosy license locker manufacture materials medical officer ment mental minimum wage nursing unit officer in charge operation paragraph patients payment performance period person personnel piecework port prescribed prior Public Contracts Act Public Health Service purposes pursuant quarantine rates record Regular Corps regulations retired Secretary smallpox specifications Standard Form storage submitted Subpart supplies surety Surgeon thereof tion toilet treatment tuberculosis typhus vessel or aircraft Walsh-Healey Public Contracts week of 40 yellow fever
인기 인용구
18 페이지 - Contractor charged with liquidated or actual damages, as provided in paragraph (b) hereof because of any delays in the completion of the work due to unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including, but not restricted to, acts of God, or of the public enemy, acts of the Government, in either its sovereign or contractual capacity, acts of another contractor in the performance of a contract with the Government, fires, floods, epidemics, quarantine...
20 페이지 - ... regardless of any contractual relationship which may be alleged to exist between the contractor or subcontractor and such laborers and mechanics...
51 페이지 - The delay in the completion of the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor...
20 페이지 - ... the Government may, by written notice to the contractor, terminate his right to proceed with the work or such part of the work as to which there has been a failure to pay said required wages and to prosecute the work to completion by contract or otherwise, and the contractor and his sureties shall be liable to the Government for any excess costs occasioned the Government thereby.
86 페이지 - ... responsible to or subject to the supervision or direction of any officer, employee, or agent engaged in the performance of investigative or prosecuting functions for any agency.
20 페이지 - States, or if articles, materials, or supplies of the class or kind to be used or the articles, materials, or supplies from which they are manufactured are not mined, produced, or manufactured, as the case may be, in the United States in sufficient and reasonably available commercial quantities and of a satisfactory quality.
20 페이지 - ... all mechanics and laborers employed directly upon the site of the work...
17 페이지 - CHANGES The Contracting Officer may at any time, by a written order, and without notice to the sureties, make changes, within the general scope of this contract, in any one or more of the following...
xii 페이지 - SUBTITLE A — Office of the Secretary of the Interior SUBTITLE B — Regulations Relating to Public Lands I Bureau of Land Management, Department of the Interior II Bureau of Reclamation, Department of the Interior Title 44 — Public Property and Works I General Services Administration III Department of State IV...
168 페이지 - Hospital" includes public health centers and general ,tuberculosis, mental, chronic disease, and other types of hospitals, and related facilities, such as laboratories, out-patient departments, nurses' home and training facilities, and central service facilities operated in connection with hospitals, but does not include any hospital furnishing primarily domiciliary care.